FAR 52.211-11 - Liquidated Damages–Supplies, Services, or Research and Development
Prescribed in 11.503(a) | |
Effective Date: | 1 September 2000 |
Clause or Provision: | Clause |
Provision or Clause Number: | 52.211-11 - Liquidated Damages–Supplies, Services, or Research and Development |
Principle Type And/Or Purpose of Contract: | |
Required: | |
Applicable: | Time and Materials/Labor Hour; |
Optional: | |
Subject: | |
ProcurementType: | |
Contract Threshold: | |
Prescription Overview: |
Prescription(a) Use the clause at 52.211-11, Liquidated Damages—Supplies, Services, or Research and Development, in fixed-price solicitations and contracts for supplies, services, or research and development when the contracting officer determines that liquidated damages are appropriate (see 11.501(a)). |
Clause Overview: |
Clause(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $__________ per calendar day of delay [Contracting Officer insert amount].
|
Important Notes/Requirements: | |
Subcontract Threshold: | |
Incorporated by Reference: | Yes |
Uniform Contract Format: | F |
Editor: | Marshall |
Personal notes.