Difference between revisions of "FAR 52.211-11 - Liquidated Damages–Supplies, Services, or Research and Development"
Line 2: | Line 2: | ||
|EffectiveDate=2000/09/01 | |EffectiveDate=2000/09/01 | ||
|ClauseorProvision=Clause | |ClauseorProvision=Clause | ||
− | |||
− | |||
|Prescribedin=11.503(a) | |Prescribedin=11.503(a) | ||
|TypePurposeContract=Time and Materials/Labor Hour -A | |TypePurposeContract=Time and Materials/Labor Hour -A | ||
+ | |CCSubject=Damages | ||
|PrescriptionOverview===Prescription== | |PrescriptionOverview===Prescription== | ||
− | (a) Use the clause at 52.211-11, Liquidated Damages—Supplies, Services, or Research and Development, in '''fixed-price solicitations and contracts''' for supplies, services, or research and development when the contracting officer determines that liquidated damages are appropriate (see 11.501(a)). | + | (a) Use the clause at 52.211-11, Liquidated Damages—Supplies, Services, or Research and Development, in '''fixed-price solicitations and contracts''' for supplies, services, or research and development when the contracting officer determines that liquidated damages are appropriate (see 11.501(a)). |
− | + | ||
− | + | ||
|FARClauseOverview===Clause== | |FARClauseOverview===Clause== | ||
'''(a)''' If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $__________ per calendar day of delay [Contracting Officer insert amount]. | '''(a)''' If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $__________ per calendar day of delay [Contracting Officer insert amount]. | ||
Line 17: | Line 14: | ||
− | '''(c)''' The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default—Fixed-Price Supply and Service clause in this contract. | + | '''(c)''' The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default—Fixed-Price Supply and Service clause in this contract. |
− | + | ||
− | + | ||
|ImportantNotesRequirements=[[Category:FAR 52 - Solicitation Provisions and Contract Clauses]] | |ImportantNotesRequirements=[[Category:FAR 52 - Solicitation Provisions and Contract Clauses]] | ||
|IncorporatedbyReference=Yes | |IncorporatedbyReference=Yes | ||
|UniformContractFormat=F | |UniformContractFormat=F | ||
|Editor=Marshall | |Editor=Marshall | ||
+ | |PurposeofContractCTI=Service, Research & Development, Supply | ||
+ | |TypeofContract=Fixed Price | ||
|ProvisionClauseNumberAlternate=52.211-11 | |ProvisionClauseNumberAlternate=52.211-11 | ||
|ProvisionClauseDescription=- | |ProvisionClauseDescription=- |
Revision as of 10:27, 1 December 2014
Prescribed in 11.503(a) | |
Effective Date: | 1 September 2000 |
Clause or Provision: | Clause |
Provision or Clause Number: | 52.211-11 - Liquidated Damages–Supplies, Services, or Research and Development |
Principle Type And/Or Purpose of Contract: | |
Required: | |
Applicable: | Time and Materials/Labor Hour; |
Optional: | |
Subject: | Damages |
ProcurementType: | |
Contract Threshold: | |
Prescription Overview: |
Prescription(a) Use the clause at 52.211-11, Liquidated Damages—Supplies, Services, or Research and Development, in fixed-price solicitations and contracts for supplies, services, or research and development when the contracting officer determines that liquidated damages are appropriate (see 11.501(a)). |
Clause Overview: |
Clause(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $__________ per calendar day of delay [Contracting Officer insert amount].
|
Important Notes/Requirements: | |
Subcontract Threshold: | |
Incorporated by Reference: | Yes |
Uniform Contract Format: | F |
Editor: | Marshall |
Personal notes.