Difference between revisions of "FAR 52.236-13 - Accident Prevention"
(2 intermediate revisions by one user not shown) | |||
Line 2: | Line 2: | ||
|EffectiveDate=1991/11/01 | |EffectiveDate=1991/11/01 | ||
|ClauseorProvision=Clause | |ClauseorProvision=Clause | ||
− | |||
|Prescribedin=36.513 | |Prescribedin=36.513 | ||
− | | | + | |TypeofContractApplicable=Dismantling, Demolition or Removal of Improvements; Fixed Price, Construction |
− | | | + | |TypeofContractOptional=Utility Services; Simplified Acquisition Procedures (Excludes Micro-Purchase); Facilities; Indefinite Delivery; Leasing of Motor Vehicles; Time & Material/Labor Hour; Cost Reimbursement, Construction; Fixed Price, Service; Cost Reimbursement, Supply; Cost Reimbursement, Service |
− | |FARClauseOverview='''(a)''' The Contractor shall provide and maintain work environments and procedures which will— | + | |PrescriptionOverview===Prescription== |
+ | |FARClauseOverview===Clause== | ||
+ | |||
+ | '''(a)''' The Contractor shall provide and maintain work environments and procedures which will— | ||
*(1) Safeguard the public and Government personnel, property, materials, supplies, and equipment exposed to Contractor operations and activities; | *(1) Safeguard the public and Government personnel, property, materials, supplies, and equipment exposed to Contractor operations and activities; | ||
*(2) Avoid interruptions of Government operations and delays in project completion dates; and | *(2) Avoid interruptions of Government operations and delays in project completion dates; and | ||
− | + | *(3) Control costs in the performance of this contract. | |
− | (3) Control costs in the performance of this contract. | + | |
Line 25: | Line 26: | ||
− | '''(e)''' The Contractor shall insert this clause, including this paragraph (e), with appropriate changes in the designation of the parties, in subcontracts. | + | '''(e)''' The Contractor shall insert this clause, including this paragraph (e), with appropriate changes in the designation of the parties, in subcontracts. |
+ | ==Alternate== | ||
+ | ===Alternate I (Nov 1991)=== | ||
+ | If the contract will involve (a) work of a long duration or hazardous nature, or (b) performance on a Government facility that on the advice of technical representatives involves hazardous materials or operations that might endanger the safety of the public and/or Government personnel or property, add the following paragraph (f) to the basic clause: | ||
+ | |||
+ | (f) Before commencing the work, the Contractor shall— | ||
+ | |||
+ | (1) Submit a written proposed plan for implementing this clause. The plan shall include an analysis of the significant hazards to life, limb, and property inherent in contract work performance and a plan for controlling these hazards; and | ||
+ | |||
+ | (2) Meet with representatives of the Contracting Officer to discuss and develop a mutual understanding relative to administration of the overall safety program. | ||
|ImportantNotesRequirements=[[Category:FAR 52 - Solicitation Provisions and Contract Clauses]] | |ImportantNotesRequirements=[[Category:FAR 52 - Solicitation Provisions and Contract Clauses]] | ||
|IncorporatedbyReference=Yes | |IncorporatedbyReference=Yes | ||
|Editor=Marshall | |Editor=Marshall | ||
+ | |ProvisionClauseNumberAlternate=52.236-13 | ||
+ | |ProvisionClauseDescription=- | ||
|Checked=no | |Checked=no | ||
|HasTermDate=2014/03/31 | |HasTermDate=2014/03/31 |
Latest revision as of 09:52, 29 December 2014
Prescribed in 36.513 | ||
Effective Date: | 1 November 1991 | |
Clause or Provision: | Clause | |
Provision or Clause Number: | 52.236-13 - Accident Prevention | |
Principle Type And/Or Purpose of Contract: | ||
Required: | ||
Applicable: | Dismantling, Demolition or Removal of Improvements; Fixed Price, Construction | |
Optional: | Utility Services; Simplified Acquisition Procedures (Excludes Micro-Purchase); Facilities; Indefinite Delivery; Leasing of Motor Vehicles; Time & Material/Labor Hour; Cost Reimbursement, Construction; Fixed Price, Service; Cost Reimbursement, Supply; Cost Reimbursement, Service | |
Subject: | ||
ProcurementType: | ||
Contract Threshold: | ||
Prescription Overview: |
Prescription | |
Clause Overview: |
Clause(a) The Contractor shall provide and maintain work environments and procedures which will—
AlternateAlternate I (Nov 1991)If the contract will involve (a) work of a long duration or hazardous nature, or (b) performance on a Government facility that on the advice of technical representatives involves hazardous materials or operations that might endanger the safety of the public and/or Government personnel or property, add the following paragraph (f) to the basic clause: (f) Before commencing the work, the Contractor shall— (1) Submit a written proposed plan for implementing this clause. The plan shall include an analysis of the significant hazards to life, limb, and property inherent in contract work performance and a plan for controlling these hazards; and (2) Meet with representatives of the Contracting Officer to discuss and develop a mutual understanding relative to administration of the overall safety program. | |
Important Notes/Requirements: | ||
Subcontract Threshold: | ||
Incorporated by Reference: | Yes | |
Uniform Contract Format: | ||
Editor: | Marshall |
Personal notes.